WIZARD DESIGN CREATIVE AGENCY CYPRUS BASED
In order to become a Client of Wizard Design Creative Agency Cyprus Based (“Wizard Design”) or a user of any of Wizard Design’s services, you agree to the following terms and conditions. Your agreement to these terms will be indicated by: the execution of any contract; commencement or completion of any business activities; or use of any of Wizard Design’s services, whichever occurs first.
1. OVERVIEW
1.1. These terms and conditions shall govern the provision of design, marketing, website and any related services by Wizard Design.
1.2. Please read these terms and conditions carefully. If you do not accept these terms and conditions without modification, you may not use Wizard Design’s services. Wizard Design may revise these terms and conditions at any time by updating this posting. If the terms and conditions are revised, the original terms accepted by the Client for a project will remain valid.
2. EXCLUSION AND LIMITATION OF LIABILITY
2.1. To the full extent permitted by law, Wizard Design hereby excludes all warranties not expressly set out herein except specifically set forth elsewhere in this agreement and gives no express or implied warranties including the warranties of merchantability or fitness for particular purpose, or arising from a course of dealing, usage, trade practice, with respect to any goods or services under or incidental to this agreement. No oral or written information or advice given by Wizard Design, our resellers, agents, representatives or employees shall create a warranty or in any way increase scope of the express warranties hereby given, and you may not rely on any such information or advice.
2.2. Wizard Design’s total aggregate liability to you for any claim in contract, negligence or otherwise arising out of or in connection to the provision of the Services shall be limited to the charges by you in respect of the Services which are the subject of any such claim.
2.3. In no event shall Wizard Design be liable to you for any loss of business, profits or anticipated savings or for any other indirect consequential or economic loss whatsoever.
3. PROPERTY RIGHTS AND OTHER CONSENTS
The Client is solely responsible for obtaining any and all necessary intellectual rights clearances and/or other consents and authorizations.
4. INDEMNITY
The Client agrees to indemnify and keep indemnified and hold Wizard Design harmless against any claim brought against Wizard Design by a third party resulting from the provision of services by Wizard Design to the Client. This includes all losses, costs, actions, proceedings, damages, expenses (including reasonable legal costs) or liabilities, whatsoever suffered and howsoever incurred in consequence of the Client’s breach or non-observance of these terms.
5. SEVERABILITY
If any clause of these terms and conditions is held to be invalid or unenforceable in whole or in part, the invalid or unenforceable shall be deemed to be omitted.
6. ASSIGNMENT
The benefit of this agreement may be assigned by Wizard Design, but not by the Client. Wizard Design may give notice to the Client in writing, and the Client’s failure to respond will be deemed acceptance. The Client may transfer this agreement provided that the Client gives Wizard Design notice in the form Wizard Design requires (setting out the details of the assignee) including payment of any transfer fee specified by Wizard Design. No other transfer by the Client is permitted.
7. ENTIRE AGREEMENT
These terms and conditions constitute the entire agreement and supersede all prior agreements, understandings, representations whether oral or written. No oral explanation or information given by any party shall alter the interpretation of these terms and conditions. Except as provided above, no variation be made to the contract unless it is in writing and signed by representatives of the Client.
8. ENTIRE AGREEMENT, GOVERNING LAW
This agreement shall be governed by the laws in force in the State of Victoria. Both parties hereby submit to the exclusivity of the Courts of that State.
9. GST
9.1 Expressions used in this clause and in the GST Act have the same meanings as when used in the GST Act.
9.2 Amounts payable and consideration provided under or in respect of this Agreement are GST exclusive.
9.3 The recipient of a taxable supply made under or in respect of this lease must pay to the supplier, at the time the consideration for the supply that is due, the GST payable in respect of the supply. This obligation extends to supply consisting of a party’s entry into this Agreement.
9.4 An amount payable by the Client in respect of a creditable acquisition by Wizard Design from a third party must not exceed the sum of the value of Wizard Design’s acquisition and the additional amount payable by the Client under this Clause on account of Wizard Design’s liability for GST.
9.5 A party is not obliged to pay GST on a taxable supply to it under this Agreement until given a valid invoice for the supply.
10. PRICING AND PROCEDURES
10.1 Prices are valid for 30 days from the date of the estimate or proposal. If work is not commenced within 30 days of acceptance, Wizard Design reserves the right to re-negotiate the price.
10.2 In some instance, Wizard Design may require that the Client pay up to a 50% deposit or full payment on completion or delivery of artwork or printed materials. In other cases, payment is due in 30 days from the date of invoice.
10.3 The Client agrees to provide written acceptance or email acceptance before any work is commenced. This must be formatted as a Letter of Agreement between the Client and Wizard Design concerning the work outlined in the Wizard Design estimate.
10.4 All pricing supplied in estimates and advertised in the Wizard Design catalogue or promotional material excludes GST.
10.5 If Wizard Design feels that any item requested by the Client does not fit within the initial brief, the Client may be charged additional fees. The item will either be quoted separately or charged as an extra, at full hourly rates.
10.6 The placement of an order for design and/or any other services offered by Wizard Design and validated by either the Client’s signature on the estimate or quotation form, or Client email or Client verbal acceptance (in the case of work with urgent timelines) constitute acceptance of the estimate or quotation and agreement to fully comply with all the Terms and Conditions.
10.7 In the event that any material necessary for the production of the project needs to be shipped to a third party (for example, for additional processing, typesetting, photographic work, colour separation, press work, or binding), Wizard Design will incur no liability for losses incurred in transit or due to the delay of a third party.
10.8 The Client is responsible for any shipping/transport or insurance costs related to the work unless specified in writing. Many of Wizard Design’s prices, where specified, include transport to one metropolitan point in Melbourne, this does not include insurance. A Client needs to request insurance in writing and pay for it if this is required.
10.9 Wizard Design shall not incur a liability or penalty for delays in the completion of the work due to action or negligence of the Client, unusual transportation delays, unforseen illness or external forces beyond the control of Wizard Design. If such event(s) occur, it shall entitle Wizard Design to extend the completion\delivery date by the time equivalent to the period of such delay. Wizard Design may from time to time and without notice or liability to you suspend any of the services if the reason for doing so is an event beyond the reasonable control of Wizard Design.
10.10 Wizard Design reserves the right to suspend services in any case where the Client fails to perform its obligations under this agreement.
10.11 All advertising of pricing is subject to change at any time without notice.
10.12 Additional charges may be added to an estimate for costs incurred for services or items required to complete a job for the Client. These may include edits, courier fees, proofing/printouts, artwork retrieval and the purchase of imagery and materials, or services supplied by third parties.
10.13 All prices quoted are, in the absence of specific written agreement to the contrary, estimates only. Wizard Design estimates for design or related work are based upon projected working hours at the current studio rate, plus materials and are subject to amendments on or after acceptance to meet any rise or fall in such rates or material costs. Any increased charges of costs arising from alterations or additions to the contractual specifications or to work previously approved, required to complete the job, such as edits, courier fees, proofing/printouts, artwork retrieval and the purchase of imagery and materials, or services supplied by third parties may be charged to the Client.
10.14 Payment for services and products is accepted via electronic funds transfer (EFT), Cheque and credit card. Accepted credit cards are Visa and MasterCard. If payment is made via credit card an additional 2% charge will be added.
11. PAYMENT
11.1 Wizard Design will provide a tax invoice for all projects completed or in progressed for immediate payment as specified on the tax invoice. Clients may apply for a 30 day credit account, if application is approved the client will receive a 30 day period from the time of invoicing when payment is required to be paid.
11.2 A deposit of up to 50% may be required before design work can commence, with the remaining amount payable on completion.
11.3 When a project extends 30 days past the commencement date or when specific project milestones are reached, Wizard Design reserves the right to issue the Client with a ‘progress payment’ invoice.
11.4 When a design is completed and requires print or manufacture to complete the project, an invoice is issued at the time it is sent to print/production. Delivery of the product will arrive prior to the 30 days allowed for payment.
11.5 Websites – Due to the segmented stages of website design and development, websites require a deposit of 25% followed by progress payments of 3 x 25% intervals or invoicing when specific milestones are reached throughout the project.
11.6 Payment is always required within the time frame specified on the invoice. If payment is not received within the specified period, Wizard Design reserves the right to charge interest on the outstanding amount until the overdue account is paid in full.
11.7 For retainer contracts an invoice will be supplied at the end of every month, which will require payment within 30 days. If for some reason the client wishes to conclude the retainer agreement early they will be liable for the full amount of the remainder of the retainer contract, less a 10% discount and payment within 30 days of the agreement conclusion.
11.8 If a client does not pay within the specified terms of the invoice Wizard Design Creative has the right to charge a late fee on the outstanding amount. The late fee based on a rate of 5% annual interest. The interest rate is calculated annually and divided by 12 to give the monthly fee associated to the outstanding amount. A late fee will be charged when an account is overdue by more than 30 days after the specified terms.
12. ARTWORK SPECIFICATIONS
12.1 When accepting artwork proofs, the Client is held fully responsible for accepting all content. This includes design, spelling, grammar and quality. It is the Client’s responsibility to request another copy if the proof is difficult to read or if changes are required. The Client’s final accepted proof is what will be printed. There will be no reprints at Wizard Design’s expense.
12.2 Clients who send in their own artwork are fully responsible for the end result. Clients are reminded to submit print-ready artwork with the correct specifications. We will print whatever you submit, but take no responsibility for artwork mistakes or product quality. There will be no reprints at Wizard Design’s expense.
12.3 Clients are reminded that when their artwork is trimmed, the bleed cut can vary in position up to 2-3 mm hence a 3mm internal margin from the bleed line is required.
12.4 It is the Client’s responsibility to ensure that any design that is submitted does not violate Australian law. Wizard Design will assume the artwork or content the Client submits is legally the Client’s property and the Client indemnifies Wizard Design accordingly.
12.5 If errors are noticed and if changes are required to your artwork, Wizard Design will contact you to avoid possible printing problems occurring. An artwork fee will be charged for any changes required. There will be no reprints at Wizard Design’s expense.
12.6 Laser proofs, digital proofs and screen proofs are not 100% accurate and variation may occur due to printing method, type of proof and the medium that the artwork is printed on. Wizard Design attempts to minimise variations as best as possible and cannot be held responsible for any deviation from the Client’s expectations as long as it is fit for the purpose. To ensure accuracy, Clients may request a press check.
12.7 Should there be a change of direction or new concept that differs from the initial brief, additional fees will be payable according to time/materials involved. Wizard Design will notify you of this and the additional quote/s will be provided.
12.8 Your artwork, photographs, images, websites and data will not be archived or stored unless specifically agreed in writing by Wizard Design prior to the work commencing. Wizard Design holds no responsibility for archiving artwork, photographs, images, websites and data and has no obligation to replace or provide any of these items after they have been completed and supplied for their single specific purpose as outlined in the approved estimate agreement.
13. WEBSITE DESIGN, MAINTENANCE AND SUPPORT
13.1 Wizard Design takes no responsibility for any errors in the content. It is the responsibility of the Client to ensure all content is correct before delivery. All images provided by the Client for their website must be copyright approved before delivery. Wizard Design is not responsible for the copyright of any supplied images. However, Wizard Design can source a range of (watermarked demo) stock images for the Client. These stock images must be purchased prior to use on the final site and will be in addition to the original quoted price, unless otherwise stated.
13.2 All content should be delivered in one package, containing all images, text, captions etc. together with clear instructions on where the content is to go.
13.3 Once the web design is complete, Wizard Design will provide the Client with the opportunity to review the resulting work. Wizard Design will make two sets of minor changes at no extra cost within 30 days of the start of the review period. Minor changes include small text changes and small adjustments to placement of items on the page. It does not include changes to images, colour schemes, template structures, module additions or any navigation features. Any minor changes can be notified to Wizard Design by e-mail or confirmed in writing. Wizard Design will consider that the Client has accepted the original draft, if no notification of changes is received in writing or via email from the Client, within 30 days of the start of the review period.
13.4 Once a site has been approved and signed off, all additional corrections and modifications to the site will be charged as extras at full hourly rates.
13.5 Technical assistance via telephone or email will be offered during the 30 day cooling off period, once a site goes live or once a client is given access to the backend of your website, which ever occurs first. Site maintenance or extensive queries (more than 15 minutes) will be charged at hourly rates.
Website support after the 30 day review period (30 days from going live) is limited to 15minutes per month phone support. Any additional support outside this timeframe may incur additional costs. Support requests should use Wizard Design’s Website Support Ticketing System. You can provide as many ticketed requests as you require. If the response to a ticket request warrants a charge, Wizard Design will inform you of the cost and seek agreement prior to proceeding further. *Basic support For any Business who purchases a Website Maintenance Package Wizard Design will offer basic phone support of what is seen as a reasonable amount. This means we will answer and offer advice and support on use of your CMS system for up to 15mins per month. Anything outside this may attract additional charges. Any additional charges will be advised and agreed to prior to proceeding with the additional advice or service.
13.6 Wizard Design will endeavour to ensure that any developed/designed website, eNewsletter, esignature or application will function correctly on the server on which it is initially installed and that it will function correctly when viewed with web browsing software. Wizard Design cannot guarantee a correct or identical function with all browser software.
13.7 Wizard Design requires 30 days written or faxed notice of cancellation of website hosting. If Website hosting has been purchased for a 12 month period there is no refund for the remainder of the 12 month contract.
13.8 Wizard Design offers maintenance packages for websites. You will need to refer to the specific inclusions of your package contract as packages vary depending on price and requirements. If a maintenance package is in place, the use of maintenance hours may include some of the following services: content updating, web page design, search engine optimisation, online marketing and research.
13.9 Wizard Design shall make reasonable efforts to provide continuing Client availability to the Server and the Services but shall not be liable for service interruptions or down time of the Server.
13.10 Wizard Design restricts access to the html code and CSS of its websites to protect the websites from being modified, incorrectly coded, and from loss of coding data. It is also a measure of intellectual property protection of Wizard Design’s code.
13.11 Wizard Design owns the intellectual property of the items designed, created and coded (see section 15) of any of Wizard Design’s websites. When websites are built by Wizard Design creative in a particular content management system (CMS), the website must remain in this CMS system and cannot be moved to an alternative hosting or CMS.
13.12 It is the client’s responsibility to input content (text, images and links) into eNewsletter (eMarketing) templates created by Wizard Design in the Business Catalyst system and/or other systems. Wizard Design takes no responsibility for the content inputted or sent out to recipients from the emarketing system.
13.13 The hosting level and the system used for eNewsletters will determine the way in which you will purchase credits to send eMarketing to recipients. Many of the Business Catalyst hosting options provide a complimentary monthly amount of emails that can be sent. Complimentary emails do not accrue. If you need to purchase additional emails you may need to contact your account manager at Wizard Design.
13.14 Most websites that Wizard Design creates with a content management system have a database. Often the Database captures information from various forms such as contact and sign up forms. It is the responsibility of the client to maintain their database, upload additional contacts, clean their database (unsubscribes, bounces) and segment/sort their database. Clients can also upload additional information from external sources into their database. Wizard Design takes no responsibility for the upload of database information or for any data stored in the database. It is the client’s responsibility to back up their data at regular intervals.
13.15 Website Reporting. Wizard Design will provide an overview of the Reporting and Analytics section of the Business Catalyst platform as part of the training session, where visitor interaction with the website is tracked and recorded. However it is up to you, the client, to fully familiarise yourself with the Reporting Tools, and use these as required by you to your organisation’s unique and specific needs. Every client has different reporting needs and as such Wizard Design can not cover all variables. Therefore only a general overview is provided.
13.16 Wizard Design does not offer full access to the back end of the Business Catalyst CMS system. This means clients are limited to content access only. Clients do not have access to any structural or functional components of the website that effect the overall operation of the site. This means no access to templates, CSS, HTML, code, forms or module specific templates.
Exception to 13.16 – Only if granted in writing by Wizard Design Creative
If an exception is made to this term and Wizard Design agrees in writing to provide full access to the the back end of the website, then Wizard Design takes no responsibility for any errors or damage to the functionality or operation of the website and it is the responsibility of the Client to ensure the website is functioning correctly. If errors or damage to the functionality occurs, Wizard Design is not liable for any financial or data losses and the client may be liable for the costs associated with repair of the website back end. This includes, but is not limited to: Page and module templates; CSS, HTML and Javascript code; Web app, CRM and eCommerce database content and functionality; Form code and data; Assets saved in the File Manager, Secure Zone functionality, URL Redirects, all module content, System Emails and Pages, Site URL settings, Administrator access levels and associated Workflow behaviours, eCommerce payment gateway connections and purchase histories, Event Booking functionality and history.
14. WEB HOSTING
14.1 The Client is solely responsible for maintaining adequate backups of their website content.
14.3 Wizard Design will endeavour to maintain network stability and satisfactory service levels however:
Servers used by Wizard Design may from time to time perform routine maintenance, services and upgrades.
Wizard Design will undertake to act on such instances at the most convenient times and provide reasonable notice by any means Wizard Design may deem satisfactory.
Servers used by Wizard Design may experience outages beyond Wizard Design’s control.
At Wizard Design’s discretion, Wizard Design may provide notification of outages whether planned or unplanned.
14.4 The Client releases Wizard Design from any claim or potential claim with relation to outages and any loss of business/service suffered by the Client or any third party.
14.5 Wizard Design cannot guarantee the availability of any domain name. Where Wizard Design is to register a domain name on behalf of a Client it will endeavour to do so, but the Client should not assume a successful registration.
14.6 Due to the infinite number of considerations that search engines use when determining a site’s ranking, Wizard Design cannot guarantee any particular placement. Acceptance by a search engine cannot be guaranteed and when a site is accepted, the time it takes to appear in search results varies from one search engine to another. Rankings will also often vary as new sites are added.
14.7 Wizard Design may discontinue services if an amount payable to Wizard Design is overdue or take down a website permanently in any case where an amount payable is overdue by more than 10 days. In any such event, the Client remains liable for the total cost of the contract including all disbursements unless otherwise agreed between the parties.
14.8 The Client agrees to allow Wizard Design to place a small credit on printed material, exhibition displays, advertisements and/or a Wizard Design credit on the Client’s website. This will be in the form of a small logo or line of text placed towards the bottom of the page. On websites this will link to Wizard Design’s own website.
14.9 The Client also agrees to allow Wizard Design to showcase the Client’s websites and other designs, along with a link to the Client’s site on Wizard Design’s own website for promotional purposes.
14.10 Wizard Design offers a range of hosting levels each with different inclusions and different pricing. Hosting prices may reasonably vary without notice.
14.11 Websites hosted by Wizard Design must be hosted on the Business Catalyst content management system unless another agreement has been arranged and formalised in writing.
15. INTELLECTUAL PROPERTY
15.1 Wizard Design is the owner of all intellectual property including copyright in all artistic and literary works (including but not limited to logos, images, designs, photographs and website code – the “Works”) created by Wizard Design or its agents.
15.2 The Works have been created for the Client for a specific purpose. Wizard Design licences the Client to use the Works for the Client’s specific purpose only. The Works may not be used for any other purpose unless authorisation is given in writing from Wizard Design. Wizard Design does not authorise the perpetual use of the Works, nor any reproduction, selling or hire of the Works or any items or materials used in the Works supplied by third parties.
15.3 Wizard Design retains the right to use the Works in any of its own marketing collateral.
15.4 Wizard Design’s rights will not affect any pre-existing intellectual property rights of terms or materials used in the Works. For example, Wizard Design may make use of external image libraries and text, images, materials and ideas supplied by the Client or a third party. If the Client provides any items or materials to Wizard Design for use in the Works, the Client warrants that the use of the items or materials will not infringe the rights of any third party and indemnifies Wizard Design for any loss or damage arising from any such infringement.
15.5 The sole exception to the above is logo design and supply. Logos developed and produced will remain the intellectual property of Wizard Design until the logo is finalised and full payment for its creation has been received. On receipt of payment in full for the logo design, full intellectual property rights will be assigned to the Client. Wizard Design reserves the right to use the logo in any of its marketing material and items.
16. TRADE MARKS
16.1 Any design work created by Wizard Design over which the Client obtains ownership will not automatically be protected by a trade mark. This includes items such as Logos, Words, Names, Images, Branding, an aspect of shape, colour, sound or scent – or any combination of these.
16.2 It is the responsibility of the Client and/or owner to investigate the availability or possibility of registering the work as a trademark and also to undertake the process of registration.
17. SOLICITATION OF EMPLOYEES
Throughout the duration of any project and for a period of 24 months thereafter, the Client shall not solicit or endeavour to entice away an employee, agent or any sub-contractors, employees or agents of Wizard Design with an offer of employment unless Wizard Design has expressed permission in writing for that offer to take place.
18. VOUCHERS
Wizard Design’s vouchers can only be used for Wizard Design’s in-house creative services which include Graphic Design, Website Design and Development and Photography (It cannot be used for any services of manufacture or where a third party supply is involved). Due to the in-house creative services being Melbourne based, some services that are not easily transferable interstate are only available in Melbourne – An example of this is Photography. The voucher is required to be used within the specified period noted on the voucher. A voucher is not valid if does not contain an approval signature of an authorised Wizard Design employee, voucher number and validation period (Validation period must be 12 months or less). Wizard Design reserves the right to change the terms of its voucher at any time. Vouchers to a value more than $500 ex gst require a signature from the Director to be valid. Vouchers can not be used in conjunction with an other offer or with any other voucher.
We are committed to protecting the privacy of your personal information. We do not sell or otherwise disclose personally identifiable information in violation of the commitment set out in this Statement.
We collect and hold the following types of information:
Information about individuals who are clients or potential clients as given to us by those individuals;
Information about roles, means of communication with and personal attributes of officers, employees and other representatives of corporations with whom we deal collected incidentally in the course of dealing with those corporations.
Information is held in hard copy and electronic records in data storage systems which permit lawful access only by those company officers and employees who need access to perform their functions. It is destroyed when it is no longer useful or is unreliable and cannot be corrected.
We gather personal information about you for the purpose of:
Marketing, supplying or delivering our products and services to you;
Improving and developing our products and services;
Expanding our business.
We may from time to time employ other companies and individuals to perform functions on our behalf e.g. we may retain a third party contractor to deal with product orders and delivery of products to you. In those circumstances we may disclose personal information to such companies and individuals to enable them to deliver services on our behalf.
You are able to request access to your personal information in accordance with the National Privacy Principals. If you wish to access your personal information please contact Wizard Design Creative at info(at)Wizard-Design.com.cy’
We will only collect personal information to the extent deemed reasonably necessary to serve our legitimate business purposes. We will store any information that you provide securely and will not sell or release it to any other business or person.
